Yew Huoi, How & Associates | Leading Malaysia Law Firm

Menu

BREACH OF CONTRACT – COURT OF APPEAL AFFIRMS LAD: CONTRACTOR LIABLE FOR DELAY, EXTRA CLAIMS REJECTED

1. Summary and Facts

In Savelite Engineering Sdn Bhd v Askey Media Technology Sdn Bhd and another appeal [2025] MLJU 2258, Askey Media engaged Savelite to construct a factory in Penang for RM8.6 million, with a completion date of 4 September 2016 and liquidated and ascertained damages (“LAD”) fixed at RM3,300 per day. Practical completion was only certified on 15 September 2017 – a delay of 376 days. The Superintending Officer (“SO”) granted an extension of time (“EOT”) of 143 days, leaving Savelite liable for 233 days of LAD amounting to RM768,900.

Askey Media also claimed loss of rental profits and indemnity payments to its tenant arising from the delay. The High Court allowed the LAD but dismissed the additional claims. Both parties appealed.

2. Legal Issues

• Whether the defendant was estopped from denying that time was of the essence, having accepted the Certificate of Non-Completion (“CNC”) and submitted multiple EOT applications.
• Whether the Plaintiff or Defendant was responsible for the delay.
• Whether time was the essence of the contract.
• Whether the quantum of damages was proportionate and reasonable.

3. Court’s Findings

• The court dismissed both appeals from the plaintiff and defendant.
• The delay was attributable to the Defendant, as time was of the essence in the contract, and the slow progress of works resulted in the delay.
• The Court varied the High Court’s order by imposing 5% interest per annum on the liquidated damages award, effective from 26.1.2017 until full settlement, pursuant to its discretion, as provided for under the contract.
• Equitable estoppel did not apply as the contract expressly stipulated that time was of the essence, and the completion deadline was clear.

4. Practical Implications

This decision affirms several important legal principles governing the contract including:
• The liquidated damages clauses are generally enforceable, provided they are genuine pre-estimate of loss and not a penalty.
• The burden lies upon the contractor to establish that a delay is excusable, as failure to do so renders the contractor liable for liquidated damages.
• The contract must be properly drafted for liquidated damages clauses as it will put the developers or employers a strong legal protection in the event of delay.

Back to Latest Legal Updates

Sorotan Terkini

LEGAL UPDATES – THE SILENT CURVE: WHY MEDICAL PREMIUMS SUDDENLY SPIKE

Medical insurance premiums do not increase gradually. They rise exponentially. For many years, costs appear manageable, giving policyholders a false sense of stability. However, once the insured reaches their mid-60s, medical charges begin to accelerate sharply, and after age 70, they often outpace the premiums by several multiples.

This happens because medical insurance is funded from a finite pool of money – an investment “bucket” – while the medical rider functions like an engine that consumes more fuel as the insured ages. When the engine grows faster than the bucket can be replenished, depletion is inevitable. The result is sudden premium hikes, demands for top-ups, or policy lapse – not due to misconduct or missed payments, but due to the structural design of the product itself.

Read More »
8 Februari ,2026 Tiada Ulasan

THE ‘COVER UNTIL 99’ MYTH – WHY INSURANCE AGENTS GET IT WRONG

Consumers must stop relying on what insurance agents say and start reading what insurance policies actually provide. ‘Medical cover until 99’ does not mean guaranteed coverage at an affordable premium. In reality, medical insurance charges rise exponentially after age 70, often making the policy mathematically unsustainable. By the time policyholders realise this, they are told to top up tens of thousands of ringgit or lose coverage altogether.

Read More »
8 Februari ,2026 Tiada Ulasan

STRATA TITLES ACT – DEVELOPER MUST ACCOUNT FOR COMMON PROPERTY COMPENSATION: HIGH COURT IMPOSES CONSTRUCTIVE TRUST

In JMB Kelana Square v Perantara Properties Sdn Bhd & Ors [2025] 12 MLJ 51, the High Court held that a developer who received compensation for land compulsorily acquired for the LRT 3 project could not retain sums attributable to common property. Although the compensation was paid entirely to the developer as registered proprietor, the Court found that part of the acquired land constituted common property, and the developer therefore held RM6.05 million on constructive trust for the Joint Management Body. The decision affirms that JMBs have proprietary standing to recover compensation for common property and that courts will intervene to prevent unjust enrichment in strata developments.

Read More »
1 Februari ,2026 Tiada Ulasan

UNFAIR DISMISSAL – MEDICAL LEAVE IS NOT MISCONDUCT: HIGH COURT UPHOLDS INDUSTRIAL COURT’S PROTECTION OF SICK EMPLOYEE

In Aerodarat Services Sdn Bhd v Lawerance Raj a/l Arrulsamy & Anor [2025] 11 MLJ 26, the High Court dismissed an employer’s judicial review and affirmed that prolonged medical leave does not, by itself, amount to misconduct justifying dismissal. The Court held that the employer failed to prove the critical element of intention not to return to work or unwillingness to perform contractual duties, despite high absenteeism caused by serious illness and surgery. The ruling reinforces that employers must distinguish between genuine illness and misconduct, and cannot rely on medical absence alone to terminate employment.

Read More »
1 Februari ,2026 Tiada Ulasan

WILL AND PROBATE – COURT OF APPEAL INVALIDATES WILL OF 97-YEAR-OLD TESTATOR: CAPACITY, SUSPICION AND UNDUE INFLUENCE PROVED

In Kong Kin Lay & Ors v Kong Kin Siong & Ors [2025] 5 MLJ 891, the Court of Appeal set aside a will executed by a 97-year-old testator, holding that there was real doubt as to testamentary capacity, compounded by serious suspicious circumstances and undue influence by certain beneficiaries. The Court emphasised that while the “golden rule” is not a rule of law, failure to obtain medical confirmation of capacity where doubt exists is a grave omission. Credibility issues with the drafting solicitor, beneficiary involvement in the will’s preparation, and suppression of evidence led the Court to declare the will invalid and order intestacy.

Read More »
1 Februari ,2026 Tiada Ulasan

NOT AN ‘AGREEMENT TO AGREE’: ENGLISH COURT OF APPEAL SAVES LONG-TERM SUPPLY CONTRACT DESPITE OPEN PRICE CLAUSE

In KSY Juice Blends UK Ltd v Citrosuco GmbH [2025] 2 Lloyd’s Rep 581, the UK Court of Appeal held that a long-term supply contract was not unenforceable merely because part of the price was stated as “open price to be fixed”. The Court implied a term that, in the absence of agreement, the price would be a reasonable or market price, noting that the product’s value could be objectively benchmarked against the market price of frozen concentrated orange juice. Emphasising that courts should preserve commercial bargains rather than destroy them, the decision confirms that section 8(2) of the Sale of Goods Act 1979 operates as a saving provision, not a bar to enforceability.

Read More »
1 Februari ,2026 Tiada Ulasan
ms_MYMY
en_USEN zh_TWZH ms_MYMY
× Hubungi Kami