CONTRACT – SALE AND PURCHASE OF PROPERTY – DELIVERY OF VACANT POSSESSION

John signed a sale and purchase agreement (“SPA“) with developer Y in the year 2012 to purchase properties in the later housing plan. The SPA, on the other hand, followed the one established in schedule H of the Housing Development (Control and Licensing) Regulations 1989 (“the HDR“) with one exception: instead of 36 months, the SPA specified 54 months for vacant possession of the properties to be given to the plaintiffs. The Minister had apparently approved the EOT for 54 months in 2010. The delivery of vacant possession of their respective properties to John was in January 2017. In the ruling in Ang Ming Lee, John sued developer Y, claiming that the controller’s extension of time (“EOT”) was unlawful and that the parties were obligated to use the mandated SPA laid forth in schedule H, which only allows for a 36-month completion term. 

Q: Does the developer have the power to deviate from the terms prescribed in the statutory contract of sale in Schedule H of the HDR? 

A: Yes, back then Ang Ming Lee had not been decided. As a result, the only method for a developer to get an EOT was to hand up vacant possession and stray from the Schedule H requirements. The notion that the defendant was wrong to deviate from the terms only comes in the year 2020. 

Q: Can John argue that he has no knowledge of the extension of time? 

A: No, the reason behind this was if Developer Y obtained an extension of time before John signed the SPA. This shows that John has knowledge of the extension of time obtained by developer Y before the project begins. 

Q: Can John raise an argument in the validity of the extension of time? 

A: Yes, because the EOT is a Ministry of Housing and Local Government decision, it can only be contested through a judicial review and a writ action.

Q: Is it possible for John to file a claim for LAD before the limitation period expires?

A: It depends on when did John file a claim for LAD against developer Y for late delivery of vacant possession. This is because the cause of action accrues on the date of the SPA and not when vacant possession was delivered.

This legal updates were made based on the recent decision of the court in Chin Kok Woo & Ors v Sky Park Properties Sdn Bhd & Ors [2022] 10 MLJ 153. 

Recent Post

PROPERTY LAW – LEGAL IMPLICATIONS OF SALE AND PURCHASE AGREEMENT BREACHES AND THE RIGHT TO OFFSET IN MALAYSIAN PROPERTY TRANSACTIONS

In the realm of Malaysian property transactions, the intricacies of Sale and Purchase Agreements (SPAs) and the enforcement of Liquidated Ascertained Damages (LAD) play pivotal roles in safeguarding the interests of both developers and purchasers. This article delves into the legal framework governing the rights and obligations of parties involved in property transactions, particularly focusing on the consequences of contractual breaches and the conditions under which a purchaser can exercise the right to offset against LAD. Through the examination of relevant case law and statutory provisions, we illuminate the legal pathways available for resolving disputes arising from the failure to adhere to the terms of SPAs, thereby offering insights into the equitable administration of justice in the context of Malaysian property law.

Read More »

WINDING-UP – OFFICIAL RECEIVER AND LIQUIDATOR (“ORL”)

In cases of compulsory winding up, the court would appoint a liquidator under s.478 of the Companies Act 2016 (“CA 2016”) to expeditiously recover and realise the assets of the wound-up company for the distribution of dividends to creditors and administer any outstanding matters involving………..

Read More »

JUDICIAL REVIEW – PROCEDURAL FAIRNESS AND LOCUS STANDI

This excerpt illuminates the foundational principles of judicial review as outlined in Order 53 of the Rules of Court 2012. It highlights the criteria for challenging public decisions on grounds of illegality, irrationality, or procedural impropriety. Central to the discussion is the question of timing in judicial review applications, particularly in cases of procedural unfairness. The practical scenario underscores the significance of a “decision” by the relevant authority as a prerequisite for locus standi, drawing insights from the case of Hisham bin Halim v Maya bt Ahmad Fuad & Ors [2023] 12 MLJ 714.

Read More »

CONTRACT LAW – CONTRACTUAL INTERPRETATION REMEDIES UNVEILED: DECIPHERING CONTRACTUAL CLAUSES AND LEGAL BALANCE

This legal updates explore the principles governing the interpretation of agreements, emphasizing the importance of clarity and unambiguity in contractual terms. It delves into a key issue involving restrictions on remedies for breach of contract, shedding light on the court’s commitment to upholding plain meanings. The illustrative scenario involving shareholders X and Y dissects a pertinent clause, showcasing the delicate balance between restricting remedies and ensuring fairness in legal proceedings.

Read More »

TIME’S UP: NAVIGATING THE 12-YEAR LIMITATION

In the intricate dance of land security and loan agreements, the ticking clock of the limitation period cannot be ignored. This excerpt delves into the critical understanding of how the 12-year limitation period, as prescribed by the Limitation Act 1953, plays a pivotal role in the enforcement of property charges in Malaysia. It elucidates the start time of this countdown and its legal implications, providing a comprehensive guide for both lenders and borrowers in navigating these time-sensitive waters.

Read More »
en_USEnglish
× How can I help you?