Yew Huoi, How & Associates | Leading Malaysia Law Firm

Menu

BREACH OF CONTRACT – ACQUIESCENCE AND CLEAN HANDS: COURT OF APPEAL BARS PURCHASER FROM ENFORCING SPA

1. Summary and Facts

Vila Mekar Sdn Bhd v Wong Yie Dee [2025] MLJU 2104 concerns a Sale and Purchase Agreement (“SPA”) between Vila Mekar Sdn Bhd (Appellant/Developer) and Wong Yie Dee (Respondent/Purchaser) for the purchase of a double-storey terrace house priced at RM225,000. The Respondent paid a 5% deposit of RM11,250 and secured a Federal loan of RM180,000 from the Bahagian Pinjaman Perumahan (BPP). Under the SPA, the Appellant was required to deliver vacant possession within the stipulated period, but failed to do so. The Respondent then sought revocation of the SPA, while the Appellant insisted that the Respondent first pay compensation pursuant to the SPA before any revocation could be processed. Subsequently, BPP issued a notice cancelling the Respondent’s loan. The Appellant thereafter filed an Originating Summons to remove the caveat lodged by the Respondent over the property and served a letter purporting to terminate the SPA. The High Court dismissed the Developer’s application but allowed the Purchaser’s counterclaim for specific performance. The Developer appealed. The Appellant appealed against the High Court’s dismissal of the OS and allowed the purchaser’s claim for specific performance of SPA.

2. Legal Issues

• Whether the Purchaser had validly terminated the SPA in 2010.
• Whether the Purchaser’s failure to pay progress claims and termination of the BPP loan amounted to repudiation.
• Whether the Purchaser was entitled to equitable relief of specific performance.

3. Court’s Findings

• The Court of Appeal held that the Purchaser’s initial termination was invalid as he failed to comply with the SPA’s conditions (payment of 10% compensation).
• By tolerating the Developer’s delay and continuing under the SPA, the Purchaser acquiesced and could not later rely on delay as a ground for termination.
• The Purchaser’s failure to pay progress claims and unilateral termination of the BPP loan constituted a clear repudiation of the SPA.
• As specific performance is an equitable remedy, the Purchaser’s own breaches and conduct barred him from obtaining relief.
• The Court of Appeal allowed the Developer’s appeal, ordered removal of the Purchaser’s caveat, and set aside the High Court’s order for specific performance.

4. Practical Implications

This judgment reinforces that a purchaser cannot terminate without fulfilling stipulated conditions. Purchasers who tolerate delay lose the right to later rely on it as a ground for rescission. A purchaser in breach cannot seek equitable relief such as specific performance.

Back to Latest Legal Updates

Sorotan Terkini

CIVIL PROCEDURE – STRIKE OUT UNDER ORDER 18 RULE 19(1)(A),(B) RULES OF COURT 2012 – EXTENSION OF TIME APPLICATION

In Badan Pengurusan Subang Parkhomes v Zen Estates Sdn Bhd [2025] MLJU 3591, the High Court reaffirmed that non-compliance with Order 37 Rule 1(5) of the Rules of Court 2012 does not automatically invalidate assessment of damages proceedings. The Court held that procedural rules must be read with the overriding objective of ensuring justice, and that the six-month time limit to file a Notice of Appointment is directory, not mandatory. Finding no prejudice to the defendant and noting active case management by the plaintiff, the Court dismissed the developer’s strike-out bid and allowed an extension of time for assessment to proceed. The decision underscores the judiciary’s commitment to substantive fairness over procedural rigidity in post-judgment proceedings.

Read More »
16 November ,2025 Tiada Ulasan

TORT – PURE ECONOMIC LOSS BAR REAFFIRMED: MMC LIABLE FOR NEGLIGENCE BUT PROTECTED FROM LOST PROFIT CLAIMS

In Asia Pacific Higher Learning Sdn Bhd v Majlis Perubatan Malaysia & Anor [2025] MLJU 3144, the High Court awarded over RM2 million in damages against the Malaysian Medical Council (MMC) for negligence, breach of statutory duty, and misfeasance during its accreditation of Lincoln University College’s medical programmes. While the court allowed direct financial losses such as survey costs, it barred claims exceeding RM550 million for lost profits, reaffirming the Federal Court’s rulings in Steven Phoa and UDA Holdings that pure economic loss is not recoverable from public or statutory bodies. The second defendant was further ordered to pay RM100,000 in exemplary damages for acting with targeted malice, marking a rare personal liability finding against a regulatory officer.

Read More »
16 November ,2025 Tiada Ulasan

ERINFORD INJUNCTION – COURT OF APPEAL CLARIFIES: EX-PARTE ERINFORD INJUNCTIONS ARE THE EXCEPTION, NOT THE RULE

In Edisijuta Parking Sdn Bhd v TH Universal Builders Sdn Bhd & Anor [2025] 5 MLJ 524, the Court of Appeal clarified that ex parte Erinford injunctions at the appellate stage should only be granted in truly exceptional circumstances where giving notice would defeat the purpose of the order. Wong Kian Kheong JCA held that, under rule 50 of the Rules of the Court of Appeal 1994, such applications should generally be heard inter partes to ensure fairness and prevent abuse. Exercising powers under section 44(1) of the Courts of Judicature Act 1964, the Court granted a conditional interim Erinford injunction pending appeal, fortified by a RM200,000 deposit and an undertaking to pay damages. The ruling provides clear guidance on balancing urgency, procedural fairness, and judicial efficiency in appellate injunctions.

Read More »
16 November ,2025 Tiada Ulasan

TOTAL FAILURE CONSIDERATION – FEDERAL COURT OVERRULES BERJAYA TIMES SQUARE: TOTAL FAILURE OF CONSIDERATION REDEFINED

In Lim Swee Choo & Anor v Ong Koh Hou @ Won Kok Fong [2025] 6 MLJ 327, the Federal Court unanimously overruled Berjaya Times Square Sdn Bhd v M Concept Sdn Bhd and clarified that the doctrine of total failure of consideration applies only to restitutionary relief, not to contractual termination. The Court held that the correct test is whether the promisor has performed any part of the contractual duties in respect of which payment is due, adopting Stocznia Gdanska SA v Latvian Shipping Co [1998] 1 WLR 574. Finding that the appellants had partly performed their obligations and the respondent had derived benefits, the Court rejected the respondent’s claim for restitution and restored the appellants’ contractual claim. The landmark decision restores clarity between contract and restitution, reinforcing commercial certainty in Malaysian law.

Read More »
16 November ,2025 Tiada Ulasan

CONTRACT (BILL OF LADING) – NO DUTY TO DETECT FRAUD: COURT CLEARS MAERSK OF LIABILITY FOR FALSE CONTAINER WEIGHTS

In Stournaras Stylianos Monoprosopi EPE v Maersk A/S [2025] 2 Lloyd’s Rep 323, the English Commercial Court held that carriers are not liable for fraudulent misdeclarations by shippers where bills of lading are issued for sealed containers. The Court ruled that Maersk had no duty to verify or cross-check declared weights against Verified Gross Mass (VGM) data under the SOLAS Convention, as its obligation under the Hague Rules extended only to the apparent external condition of cargo. However, the judgment signals that a limited duty of care could arise in future where a carrier is put on notice of fraud. For now, carriers may rely on shipper declarations, but consignees must exercise commercial vigilance and due diligence when relying on bills for payment.

Read More »
16 November ,2025 Tiada Ulasan

EXEMPLARY DAMAGES – STATUTORY BODY DUTY – DAMAGES – OBTAINING APPROVAL

In Big Man Management Sdn Bhd v Tenaga Nasional Bhd [2025] 5 MLJ 290, the Federal Court reinstated nearly RM3.56 million in special damages and awarded RM100,000 in exemplary damages against TNB for wrongfully disconnecting electricity to an ice factory. The Court ruled that “strict proof” of special damages does not mean a higher burden beyond the civil standard of proof and affirmed that TNB, as a statutory monopoly, breached its statutory duty by using disconnection as leverage to collect payment. The judgment underscores that public utilities cannot misuse statutory powers, and consumers wrongfully deprived of essential services may be entitled to punitive remedies in exceptional cases.

Read More »
16 November ,2025 Tiada Ulasan
ms_MYMY
en_USEN zh_TWZH ms_MYMY
× Hubungi Kami