Yew Huoi, How & Associates | Leading Malaysia Law Firm

Menu

BREACH OF CONTRACT – ACQUIESCENCE AND CLEAN HANDS: COURT OF APPEAL BARS PURCHASER FROM ENFORCING SPA

1. Summary and Facts

Vila Mekar Sdn Bhd v Wong Yie Dee [2025] MLJU 2104 concerns a Sale and Purchase Agreement (“SPA”) between Vila Mekar Sdn Bhd (Appellant/Developer) and Wong Yie Dee (Respondent/Purchaser) for the purchase of a double-storey terrace house priced at RM225,000. The Respondent paid a 5% deposit of RM11,250 and secured a Federal loan of RM180,000 from the Bahagian Pinjaman Perumahan (BPP). Under the SPA, the Appellant was required to deliver vacant possession within the stipulated period, but failed to do so. The Respondent then sought revocation of the SPA, while the Appellant insisted that the Respondent first pay compensation pursuant to the SPA before any revocation could be processed. Subsequently, BPP issued a notice cancelling the Respondent’s loan. The Appellant thereafter filed an Originating Summons to remove the caveat lodged by the Respondent over the property and served a letter purporting to terminate the SPA. The High Court dismissed the Developer’s application but allowed the Purchaser’s counterclaim for specific performance. The Developer appealed. The Appellant appealed against the High Court’s dismissal of the OS and allowed the purchaser’s claim for specific performance of SPA.

2. Legal Issues

• Whether the Purchaser had validly terminated the SPA in 2010.
• Whether the Purchaser’s failure to pay progress claims and termination of the BPP loan amounted to repudiation.
• Whether the Purchaser was entitled to equitable relief of specific performance.

3. Court’s Findings

• The Court of Appeal held that the Purchaser’s initial termination was invalid as he failed to comply with the SPA’s conditions (payment of 10% compensation).
• By tolerating the Developer’s delay and continuing under the SPA, the Purchaser acquiesced and could not later rely on delay as a ground for termination.
• The Purchaser’s failure to pay progress claims and unilateral termination of the BPP loan constituted a clear repudiation of the SPA.
• As specific performance is an equitable remedy, the Purchaser’s own breaches and conduct barred him from obtaining relief.
• The Court of Appeal allowed the Developer’s appeal, ordered removal of the Purchaser’s caveat, and set aside the High Court’s order for specific performance.

4. Practical Implications

This judgment reinforces that a purchaser cannot terminate without fulfilling stipulated conditions. Purchasers who tolerate delay lose the right to later rely on it as a ground for rescission. A purchaser in breach cannot seek equitable relief such as specific performance.

Back to Latest Legal Updates

Recent Post

LEGAL UPDATES – THE SILENT CURVE: WHY MEDICAL PREMIUMS SUDDENLY SPIKE

Medical insurance premiums do not increase gradually. They rise exponentially. For many years, costs appear manageable, giving policyholders a false sense of stability. However, once the insured reaches their mid-60s, medical charges begin to accelerate sharply, and after age 70, they often outpace the premiums by several multiples.

This happens because medical insurance is funded from a finite pool of money – an investment “bucket” – while the medical rider functions like an engine that consumes more fuel as the insured ages. When the engine grows faster than the bucket can be replenished, depletion is inevitable. The result is sudden premium hikes, demands for top-ups, or policy lapse – not due to misconduct or missed payments, but due to the structural design of the product itself.

Read More »
8 February ,2026 尚無留言

THE ‘COVER UNTIL 99’ MYTH – WHY INSURANCE AGENTS GET IT WRONG

Consumers must stop relying on what insurance agents say and start reading what insurance policies actually provide. ‘Medical cover until 99’ does not mean guaranteed coverage at an affordable premium. In reality, medical insurance charges rise exponentially after age 70, often making the policy mathematically unsustainable. By the time policyholders realise this, they are told to top up tens of thousands of ringgit or lose coverage altogether.

Read More »
8 February ,2026 尚無留言

STRATA TITLES ACT – DEVELOPER MUST ACCOUNT FOR COMMON PROPERTY COMPENSATION: HIGH COURT IMPOSES CONSTRUCTIVE TRUST

In JMB Kelana Square v Perantara Properties Sdn Bhd & Ors [2025] 12 MLJ 51, the High Court held that a developer who received compensation for land compulsorily acquired for the LRT 3 project could not retain sums attributable to common property. Although the compensation was paid entirely to the developer as registered proprietor, the Court found that part of the acquired land constituted common property, and the developer therefore held RM6.05 million on constructive trust for the Joint Management Body. The decision affirms that JMBs have proprietary standing to recover compensation for common property and that courts will intervene to prevent unjust enrichment in strata developments.

Read More »
1 February ,2026 尚無留言

UNFAIR DISMISSAL – MEDICAL LEAVE IS NOT MISCONDUCT: HIGH COURT UPHOLDS INDUSTRIAL COURT’S PROTECTION OF SICK EMPLOYEE

In Aerodarat Services Sdn Bhd v Lawerance Raj a/l Arrulsamy & Anor [2025] 11 MLJ 26, the High Court dismissed an employer’s judicial review and affirmed that prolonged medical leave does not, by itself, amount to misconduct justifying dismissal. The Court held that the employer failed to prove the critical element of intention not to return to work or unwillingness to perform contractual duties, despite high absenteeism caused by serious illness and surgery. The ruling reinforces that employers must distinguish between genuine illness and misconduct, and cannot rely on medical absence alone to terminate employment.

Read More »
1 February ,2026 尚無留言

WILL AND PROBATE – COURT OF APPEAL INVALIDATES WILL OF 97-YEAR-OLD TESTATOR: CAPACITY, SUSPICION AND UNDUE INFLUENCE PROVED

In Kong Kin Lay & Ors v Kong Kin Siong & Ors [2025] 5 MLJ 891, the Court of Appeal set aside a will executed by a 97-year-old testator, holding that there was real doubt as to testamentary capacity, compounded by serious suspicious circumstances and undue influence by certain beneficiaries. The Court emphasised that while the “golden rule” is not a rule of law, failure to obtain medical confirmation of capacity where doubt exists is a grave omission. Credibility issues with the drafting solicitor, beneficiary involvement in the will’s preparation, and suppression of evidence led the Court to declare the will invalid and order intestacy.

Read More »
1 February ,2026 尚無留言

NOT AN ‘AGREEMENT TO AGREE’: ENGLISH COURT OF APPEAL SAVES LONG-TERM SUPPLY CONTRACT DESPITE OPEN PRICE CLAUSE

In KSY Juice Blends UK Ltd v Citrosuco GmbH [2025] 2 Lloyd’s Rep 581, the UK Court of Appeal held that a long-term supply contract was not unenforceable merely because part of the price was stated as “open price to be fixed”. The Court implied a term that, in the absence of agreement, the price would be a reasonable or market price, noting that the product’s value could be objectively benchmarked against the market price of frozen concentrated orange juice. Emphasising that courts should preserve commercial bargains rather than destroy them, the decision confirms that section 8(2) of the Sale of Goods Act 1979 operates as a saving provision, not a bar to enforceability.

Read More »
1 February ,2026 尚無留言
zh_TWZH
en_USEN ms_MYMY zh_TWZH
× 联系我们